Introduction:

Welcome to Masonary Limited! These Terms of Service (“Terms”) govern your use of our services and provide important information about our policies, practices, and legal obligations. Please take a moment to read through these Terms carefully before engaging with any of our construction, building, or design services.
At Masonary Limited, we are committed to providing high-quality construction services that meet the needs of international organizations, government agencies, and corporate clients, as well as individuals seeking reliable, scalable solutions for their projects. Whether it’s a large-scale construction project or a residential building that requires precision and craftsmanship, we are here to turn your vision into reality.
By accessing or using our services, you agree to comply with and be bound by these Terms.

1. Scope of Services

The main difference between these heat pumps is where they source their heat from – the ground or the air. Ground source heat pumps use geothermal pockets and naturally heated ground layers, whereas air source heat pumps absorb heat from the outside air. In comparison to traditional gas boiler heating systems, heat pumps have been found to be up to 400% more efficient! What’s more, they also produce 70% less carbon emissions.

2. Acceptance of Terms

By using our website or engaging our services, you acknowledge that you have read, understood, and agree to abide by these Terms. If you do not agree to these Terms, please refrain from using our website or services.

3. Service Delivery

Our team at Masonary Limited ensures that all projects are completed with the highest level of professionalism and quality. However, we acknowledge that construction timelines can be influenced by external factors such as weather conditions, site-specific challenges, and regulatory approvals.

We strive to provide timely service delivery, but unforeseen delays may occur. We will keep you informed and work with you to minimize the impact on your project.

4. Payment Terms

We offer flexible payment plans to suit different project sizes and client needs. Payment terms will be clearly outlined in the project agreement before the commencement of any work. These terms include:

Initial deposit: A percentage of the total project cost required before work begins.
Progress payments: Payments made based on project milestones or phases.
Final payment: Due upon the completion of the project, once all work has been reviewed and accepted.
We accept various payment methods, including bank transfers, cheques, and electronic payments. In the event of a delay in payments, we reserve the right to halt work until the balance is settled.

5. Client Responsibilities

As a client, you agree to provide us with all necessary documents, permits, and approvals required for the successful execution of the project. You are responsible for ensuring that your construction site complies with all local regulations and zoning laws.

Additionally, timely access to the project site is crucial to maintaining the construction schedule. If there are any changes to the scope of the project or unforeseen obstacles, these must be communicated promptly to avoid unnecessary delays.

6. Quality Assurance and Warranties

Masonary Limited takes pride in delivering exceptional quality in every project we undertake. We follow strict quality control measures and adhere to industry best practices. We provide a warranty on all our work, ensuring that if any issues arise within a specified period post-completion, we will rectify them at no extra cost to you.

Please note that warranties do not cover damages caused by external factors such as natural disasters, misuse, or unauthorized modifications to the completed structure.

7. Intellectual Property

All designs, blueprints, and other intellectual property created by Masonary Limited for your project are the property of the company unless otherwise agreed upon in writing. You may not use, reproduce, or distribute any part of the intellectual property without our prior consent.

8. Confidentiality

We understand the importance of confidentiality in construction projects, especially when dealing with sensitive corporate or government contracts. Masonary Limited agrees to keep all client information, project details, and any proprietary data confidential, unless disclosure is required by law.

9. Liability and Indemnity

While Masonary Limited endeavors to provide safe and efficient services, construction projects inherently carry some degree of risk. We are not liable for any loss, injury, or damage caused by third parties, or for circumstances beyond our control, such as force majeure events (e.g., natural disasters, civil unrest).

Clients agree to indemnify Masonary Limited against any claims, losses, or damages arising from the client’s breach of these Terms or their failure to comply with applicable laws.

10. Termination

Either party may terminate the contract with notice if there is a breach of the agreement, failure to make payments, or any other justifiable cause. Upon termination, the client agrees to settle any outstanding invoices for work completed to date.

11. Governing Law

These Terms shall be governed by the laws of the Federal Republic of Nigeria. Any disputes arising from or related to these Terms shall be subject to the exclusive jurisdiction of the courts in Nigeria.

12. Changes to Terms

Masonary Limited reserves the right to amend or update these Terms at any time. Any changes will be posted on our website, and the revised Terms will become effective upon posting. We encourage you to periodically review this page to stay informed of any updates.

13. Contact Information

If you have any questions or concerns about these Terms of Service, please contact us:


Address: 123 Construction Avenue, Victoria Island, Lagos, Nigeria
Phone: +234 701 234 5678
Email: info@masonarylimited.com 
Website: www.masonarylimited.com